[DOWNLOAD] "Quin Blair Enterprises, Inc. v. Julien Const. Co." by Supreme Court of Wyoming * Book PDF Kindle ePub Free
eBook details
- Title: Quin Blair Enterprises, Inc. v. Julien Const. Co.
- Author : Supreme Court of Wyoming
- Release Date : January 03, 1979
- Genre: Law,Books,Professional & Technical,
- Pages : * pages
- Size : 78 KB
Description
The principal questions raised in this appeal concern appropriate damages for delay in completing a building contract, the effect of a contractual provision requiring the contractor to request in writing an extension of time to complete the contract, the effect on other contract remedies of an escrow agreement and a "punch-list" which required the contractor to redo work that was incorrectly or defectively done, and the effect of a failure to timely serve notice of suit upon a surety-defendant whom plaintiff alleges is united in interest with the contractor-defendant.